32 – Improvement of water supply system

Objective of the program

To implement actions that reduce the dependence of direct water supply from the Doce River in municipalities where the supply was temporally scuppered due to the collapse. In the municipalities with more than 100,000 inhabitants, the reduction of the dependence could be over 50%, in the others over 30%. Furthermore improvements to the infrastructure of the Water Treatment Plants.

Progress of Program Select the period

On March 1, 2024, SANEAR filed a letter approving the conceptual projects for the improvements to ETAs I, II and IV of Colatina/ES.
On March 1, 2024, the SAAE of Governador Valares/MG filed a letter requesting the Renova Foundation to prepare a Technical and Economic feasibility study of the UTR model proposed for the Vila Isa and Recanto dos Sonhos ETAs.
On March 4, 2024, SAAE Governador Valadares filed a letter approving the basic project for the improvements to the ETA and new UTR Santa Rita.
On March 4, 2024, the Renova Foundation filed with SANEAR - Colatina/ES, the documents that make up the leasing study for the areas of the Marista and Nossa Senhora Aparecida UTRs.
On March 6, 2024, SANEAR - Colatina/ES filed a letter with the Renova Foundation approving the leasing studies for the areas of the Marista and Nossa Senhora Aparecida UTRs.
On March 13, 2024, the Renova Foundation filed with SANEAR - Colatina/ES, the documents that make up the basic project of the Waste Treatment Unit (UTR) at ETA Columbia.
"On March 18, 2024, the SAAE of Galiléia/MG made official to the Renova Foundation the approval of the fire and panic fighting project (SPCI) and the conceptual project and methodology for plugging leaks in the filters of the ETA of
Galiléia/MG. "
On March 19, 2024, COPASA, in a meeting with the Renova Foundation, approved the scope of the alternative water withdrawal of Tumiritinga/MG proposed by the Foundation. In this proposal, the projects were developed considering a withdrawal and supply of 15L/s and a STA capable of treating 5.7L/s (30% of the flow, according to TTAC).
On March 26, 2024, SANEAR - Colatina/ES filed a letter with the Renova Foundation approving the basic project of the UTR Columbia.

On February 5, 2024, the Renova Foundation participated in the conciliation hearings promoted by the 4th Federal Court within the scope of axis 09, to evaluate the measures already taken and referrals for the completion of works and other measures in the following locations:
- Boninsegna/ES;
- Galiléia/MG;
- Tumiritinga/MG.

On February 6, 2024, the Renova Foundation participated in the conciliation hearings promoted by the 4th Federal Court within the scope of axis 09, to evaluate the measures already taken and referrals for the completion of works and other measures in the following locations:
- São Tomé do Rio Doce/MG;
- Resplendor/MG.

On February 7, 2024, the Renova Foundation participated in the conciliation hearings promoted by the 4th Federal Court within the scope of axis 09, to evaluate the measures already taken and referrals for the completion of works and other measures in the following locations:
- Pedra Corrida/MG;
- Itueta/MG.

On February 1, 2024, the Renova Foundation filed with SANEAR - Colatina/ES, the documents that make up the conceptual project of the Waste Treatment Unit (UTR) at ETA Columbia.
On February 9, 2024, Fundação Renova filed with SAAE GV – Governador Valadares/MG the documents that make up the conceptual project of the Waste Treatment Unit (UTR) at ETA Central. This protocol is in compliance with what was decided at the conciliation hearing on October 19, 2023.

On February 9, 2024, the Renova Foundation filed with COPASA the documents that make up the detailed project for the alternative water withdrawal of the headquarters of the municipality of Tumiritinga/MG. This protocol is in compliance with what was decided at the conciliation hearing on February 5, 2024.

On February 9, 2024, the Renova Foundation filed with COPASA the documents that make up the detailed project for the Definitive Access to the ETA in the municipality of Tumiritinga/MG. This protocol is in compliance with what was decided at the conciliation hearing on February 5, 2024.

On February 15, 2024, the Renova Foundation filed with COPASA the documents that make up the detailed Automation and Telemetry project for Wells, STA and ETA in the municipality of Resplendor/MG. This protocol is in compliance with what was decided at the conciliation hearing on February 6, 2024.

On February 15, 2024, the Renova Foundation filed with COPASA the documents that make up the conceptual project of the ETA and UTR in the municipality of Itueta/MG. This protocol is in compliance with what was decided at the conciliation hearing on February 7, 2024.

On February 2, 2024, the Renova Foundation filed with SANEAR-Colatina/ES the documents that make up the conceptual project for the Complementary Improvements of ETAS (STAGE 01 – Filter Beds) in the municipality of Colatina/MG. This protocol is in compliance with what was decided at the conciliation hearing on November 28, 2023.

On February 21, 2024, the Renova Foundation filed with the CIF the Consolidated Report on Assisted Operation of the Pedra Corrida Alternative Water Supply System in compliance with deliberation no. 185, of 07/31/2018.

On February 21, 2024, the Renova Foundation filed with the CIF, the 2nd Quarter Monitoring Report on the Functionality of the Pedra Corrida Alternative Water Supply System in compliance with deliberation no. 185, of 07/31/2018.

On February 22, 2024, the Renova Foundation filed with SANEAR-Colatina/ES the documents that make up the conceptual project for the Structural Improvements of ETAS Marista, N. Sra. Aparecida and Columbia, in the municipality of Colatina/ES. This protocol is in compliance with what was decided at the conciliation hearing on November 28, 2023.

On February 15, 2024, the Renova Foundation began the Assisted Operation of the Boninsegna/ES Water Supply System.

On February 29, 2024, the Renova Foundation filed in the files of Axis 09, the Technical Proposal for Water Treatability Tests in the locations of Resplendor/MG and Itueta/MG.

On January 11, 2024, the axis 9 court summoned the Renova Foundation and other interested parties to conciliation hearings in the following locations:
Marilandia-Boninsegna/ES, Galiléia/MG, Tumiritinga-HQ/MG, Tumiritinga-São Tomé do Rio Doce/MG, Resplendor/MG, Periquito-Pedra Corrida/MG and Itueta/MG.

On January 26, 2024, the Renova Foundation filed with SAAE GV the conceptual project of the ETA Recanto do Sonhos UTR in compliance with the court decision of the 4th Federal Court.

On January 26, 2024, the Renova Foundation filed with SAAE GV the conceptual project of the UTR of the Vila Isa ETA in compliance with the judicial decision of the 4th Federal Court.

On January 10, 2024, the Renova Foundation filed with SANEAR the progress report on the emergency improvements actions at the Colatina/ES ETAs.

On 12/07/2023, the Technical Session took place, of Marco A, at the headquarters of Governador Valadares, where the Renova Foundation presented to the forensic team, in a video conference meeting via Microsoft Teams:

• The scope agreed with the SAAE of Governador Valadares for the improvements of the Central, Vila Isa and Recanto dos Sonhos ETAs;

• Definition of the interconnection of the piping of the alternative collection and adduction system and the existing pipes of the main intake at the Central WTP;

• Project documentation prepared to meet each of the scope items;

• Clarifications regarding non-conformities presented by the Expert in Expert Report ID 867501068, correlating with the respective project documents for compliance or justifications for non-compliance.

On 12/08/2023, Governador Valadares City Hall and SAAE signed the Private Instruments for Defining the Total and Final Scope of the town of Governador Valadares, considering the ETAs Central, Vila Isa, Recanto dos Sonhos and Santa Rita.

On 12/13/2023, the City of Tumiritinga signed the Term of Delivery and Receipt of Works and Closure of Assisted Operation in the location of São Tomé do Rio Doce, thus ending the implementation of the entire scope of Clause 171 in that location.

On 12/27/2023, the Renova Foundation delivered the Basic Project for the improvements to be implemented at the Santa Rita Water Treatment Station, including the Waste Treatment Unit – ETA/UTR Santa Rita for analysis and approval of the SAAE of Governador Valadares, in compliance with the court decision.

No progress this month

On July 7, 2023, in a videoconference meeting via Microsoft Teams, the Renova Foundation presented to the expert team an update on the progress of works at the Item 1 locations visited on July 4, 5 and 6, 2023.

On May 22, Alpercata City Hall signed the Term of Commitment, which establishes the total and final scope for compliance with clause 171 of the TTAC.

On March 7, 2023, in a videoconference meeting via Microsoft Teams, the Renova Foundation presented the updated summary of the status of the projects and works of the 25 locations listed in Item 1 of the Judicial Decision (ID 151060877) to the expert team.
"On March 8 and 9, 2023, the expert team carried out a technical visit to monitor the progress of the works being carried out by the Renova Foundation and subcontractors, activities related to Stage 1.3 - Works, Commissioning and Monitoring of the Work Plan, in the following locations:
• Pedra Corrida, municipality of Periquito/MG;
• Headquarters of the municipality of Governador Valadares/MG;
• Headquarters of the municipality of Tumiritinga/MG;
• São Tomé do Rio Doce, municipality of Tumiritinga/MG;
• Headquarters of the municipality of Galiléia/MG;
• Headquarters of the municipality of Resplendor/MG;
• Boninsegna, municipality of Marilândia/ES;
• Headquarters of the municipality of Baixo Guandu/ES;
• Headquarters of the municipality of Linhares/ES.
"
On March 14, 2023, COPASA formalized its disagreement with the CTSHQA regarding the capacity of the treatment system for the alternative catchment of Tumiritinga, and requested the reduction of dependence on the Doce River by 100%, in order to implement a treatment system for the total flow from well C-04.
On March 15, 2023, in a videoconference meeting via Microsoft Teams, the Renova Foundation presented an update on the progress of works in the locations visited on March 8 and 9, 2023 to the expert team.
On March 10, the waiver of environmental licensing was issued for the ETA of Boninsegna, district of Marilândia/ES.

On February 1, 2023, the Renova Foundation, the Municipality of Galiléia/MG and SAAE of Galiléia celebrate the signature of the term of delivery of the works of the Water Supply System of the Municipality.
On February 16, 2023, the Renova Foundation added to the case file a manifestation, ACP-09-PCL-020-230216.pdf, “Term of Commitment” evidencing the agreement with the Municipality of Marilândia/ES and the Autonomous Water Sanitation Service (“SAAE”) of Marilândia/ES, which aims to define the theme of water supply.
"On February 6th and 7th, 2023, the expert team carried out a technical visit to monitor the progress of the works being carried out by the Renova Foundation and subcontractors, activities related to Stage 1.3 - Works, Commissioning and Monitoring of the Work Plan, in the following locations:
• Pedra Corrida, municipality of Periquito/MG;
• Headquarters of the municipality of Governador Valadares/MG;
• Headquarters of the municipality of Tumiritinga/MG;
• São Tomé do Rio Doce, municipality of Tumiritinga/MG;
• Headquarters of the municipality of Galiléia/MG;
• Headquarters of the municipality of Resplendor/MG;
• Boninsegna, municipality of Marilândia/ES;
• Headquarters of the municipality of Baixo Guandu/ES;
• Headquarters of the municipality of Linhares/ES.
"
On February 7, 2023, in a face-to-face meeting at COPASA's regional superintendence in Ipatinga, COPASA formalized its disagreement regarding the total and final scope for definitiveness of clause 171 of the TTAC, with regard to the conditions for implementing the treatment system for water from well C-04.
On February 8, 2023, in a videoconference meeting via Microsoft Teams, the Renova Foundation presented the updated summary of the status of the projects and works of the 25 locations listed in Item 1 of the Judicial Decision (ID 151060877) to the expert team.

On December 19, 2022 - Judicial decision summoning the Parties to present a clear, specific, detailed and exhaustive statement regarding all the questions in relation to which clarifications are necessary, forming a list of questions and requests for clarification that address both the issue the merit of the expertise (requests for clarification on the scope, methodology, forwarding of work, etc.), as well as expert fees, for all phases and stages.
On December 6, 2022, the forensic team added the Expert Technical Report of Stage 1.2 to the court case file - Analysis of Schedules and Projects referring to the Pedras location, municipality of Mariana/MG (ID 1312244367).
On December 12, 2022, the forensic team added Report No. 25 - Works Monitoring 02 (ID 1316817352) to the court case file, referring to the expert work follow-up activities covering the reference period of September and October 2022 , related to Stage 1.3 – Works, Commissioning and Monitoring of the Work Plan.
On December 14, 2022, the forensic team added to the case file the Complementary Report - Clarification of the Stakeholders' Questions of Step 1.2 (Analysis of Schedules and Projects) for the Camargos location, municipality of Mariana/MG (ID 1318057388 ).
On December 19, 2022, the forensic team added the Expert Technical Report of Stage 1.2 - Analysis of Schedules and Projects referring to the Headquarters location of the municipality of Tumiritinga/MG (ID 1319861347).
On December 19, 2022, the forensic team added Report No. 27 – Complementary Analysis of Project Documentation (ID 1319903893) to the legal proceedings.
On December 2, 2022, in reference to Step 2.2 - Factual Situation, the expert team added the Expert Technical Reports Revision R00_A (ID 1313768909), referring to Territory IV, corresponding to the communities of Itueta Velha, Fazenda Boa Esperança, District of Santo Antônio do Rio Doce, Pedra Lorena, Fazenda Ilha Pedra Lorena, Córrego Barra Provisória and Fazenda Boa Vista, located in the municipalities of Aimorés/MG, Itueta/MG and Resplendor/MG.
On December 6, 2022, in reference to Step 2.2 - Factual Situation, the expert team added the Expert Technical Reports Revision R00_A (ID 1314896374), Step 2.2 - Factual Situation, referring to Territory III, corresponding to the communities of Baixada Coronel Roberto and Ipaba do Paraíso, located in the municipalities of Ipaba, Caratinga and Santana do Paraíso/MG.
On December 13, 2022, in reference to Step 2.2 – Factual Situation, the forensic team added the Expert Technical Reports Revision R00_A (ID 1317159875), referring to Territory I, corresponding to the communities of Bento Rodrigues, Ponte do Gama, Gesteira, Headquarters of Barra Longa, Santana do Deserto and Camões, located in the municipalities of Mariana/MG, Barra Longa/MG, Rio Doce/MG and Sem Peixe/MG.
On December 14, 2022, in reference to Step 2.2 - Factual Situation, the forensic team added the Expert Technical Reports Revision R00_A (ID 1318057376), referring to Territory V, corresponding to the communities of Córrego Boa Esperança, Córrego Catita, Córrego da Piaba, Córrego do Lavra, Córrego Queixadão, Fazenda Fontenelle, Fazenda Porto Esperança, Fazenda Sapucaia, Ilha Bela Vista, Itapina, Maria Ortiz, Mascarenhas, Porto Belo and Santa Joana, located in the municipalities of Baixo Guandu/ES and Colatina/ES.
On December 20, 2022, in reference to Step 2.2 - Factual Situation, the expert team added the Expert Technical Reports Revision R00_A, referring to Priority Axis No. 9 - Water Supply for Human Consumption, Step 2.2 ( Factual Situation) of Territory II, referring to the municipality of Linhares, Espírito Santo.
On December 15, 2022, the Municipal Works Secretariat of the city of Baixo Guandu, state of Espirito Santo, issued the authorization for the start of works for the implementation of the water intake pipeline in the Guandu River.

On November 03, 2022, the forensic team added Report No. 23 - Construction Monitoring 01 (ID 1301893878) to the court case file, referring to the expert activities of monitoring works between January and August 2022, related to Stage 1.3 – Works, Commissioning and Monitoring of the Work Plan, at the headquarters of Governador Valadares/MG.
On November 23, 2022, the forensic team added the Expert Technical Reports Revision R00 to the court case file referring to Priority Axis Nº 9 - Water Supply for Human Consumption, Stage 2.2 (Factual Situation) of Territory VII, referring to the Quilombola Community of Degredo, in the municipality of Linhares, Espírito Santo.
On November 29, 2022, the forensic team added the Technical Expert Report of Stage 1.2 to the court case file - Analysis of Schedules and Projects referring to the Camargos location, in the municipality of Mariana/MG.
On November 29, 2022, the forensic team added to the case file the Complementary Report of Questions from the locality Ipaba do Paraíso, municipality of Santana do Paraíso/MG, referring to the clarifications to the Questions of the Interested Parties.
On November 3, 2022, in a videoconference meeting via Microsoft Teams, the Renova Foundation presented to the expert team a summary of the history, the factual situation, the projects, the works and the water and sediment monitoring program in the region of the HQ of the municipality of Alpercata/MG.
On November 4, 2022, in a videoconference meeting via Microsoft Teams, the Renova Foundation presented the updated summary of the status of the projects and works of the 25 locations listed in Item 1 of the Judicial Decision on Priority Axis No. 9 to the expert team.
On November 7, 2022, the forensic team carried out an expert technical visit to the water supply system in the town of Alpercata/MG, in order to understand the history, factual and administrative situation, projects and works carried out and in development.
On November 9, 2022, the forensic team added to the case file the Expert Technical Report of Stage 1.2 – Analysis of Schedules and Projects referring to the locality Senhora da Penha, municipality of Fernandes Tourinho/MG (ID 1304480877).

On October 3, 2022, the forensic team added the Expert Technical Report of Stage 1.2 - Analysis of Schedules and Projects referring to the location of Boninsegna, municipality of Marilândia/ES (ID 1290321364).
On October 5, 2022, the forensic team added to the court case file the initial issue of Complementary Reports - Clarifications to the Stakeholder Questions of Step 1.2 (Analysis of Schedules and Projects) for the Headquarters of Baixo Guandu/ES, Gesteira, municipality of Barra Longa/MG and Mascarenhas, municipality of Baixo Guandu/ES (ID 1291515362).
On October 5, 2022, the forensic team added to the court case file the review of the Complementary Reports - Clarifications to the Interested Parties' Questions of Step 1.2 (Analysis of Schedules and Projects) for the locations of São Vítor, municipality of Governador Valadares/ MG, São Tomé do Rio Doce, municipality of Tumiritinga/MG and Santo Antônio do Rio Doce, municipality of Aimorés/MG (ID 1291515362).
On October 6, 2022, the forensic team added to the case file the Complementary Report - Clarification of the Stakeholders' Questions of Step 1.2 (Analysis of Schedules and Projects) for the location Boninsegna, municipality of Marilândia/ES (ID 1291959881 ).

On September 15, 2022, in a videoconference meeting via Microsoft Teams, the Renova Foundation presented to the expert team a summary of the history, the factual situation, projects, works and the water and sediment monitoring program in the region from the HQ of the municipality of Tumiritinga/MG.
On September 16, 2022, in a videoconference meeting via Microsoft Teams, the Renova Foundation presented the update on the status summary of the projects and works of the 25 locations listed in Item 1 of the Priority Axis Court Decision No. .
On September 16, 2022, the expert team added to the case file the Expert Technical Report of Stage 1.2 - Analysis of Schedules and Projects of the Work Plan for the Mascarenhas location, municipality of Baixo Guandu/ES (ID 1283468869).
On September 19, 2022, the expert team carried out a technical visit to the water treatment plant of the HQ locality of the municipality of Tumiritinga/MG, to understand the history, factual and administrative situation, projects and works under development and carried out by Renova Foundation and subcontractors.
On September 20, 2022, the expert team added to the case file the review of the Complementary Reports (ID 1285105889) - Clarification of the Stakeholders' Questions of Step 1.2 (Analysis of Schedules and Projects) for the HQ locations of Resplendor, Headquarters of Galileia, Headquarters of Governador Valadares, Headquarters of Linhares, Pedra Corrida (Periquito), Headquarters of Itueta, Perpétuo Socorro (Belo Oriente) and Regencia (Linhares), as provided for in Report No. 19 (ID 1245437782).
On September 19, 20 and 21, 2022, the expert team carried out a technical visit to monitor the execution of works carried out by the Renova Foundation and subcontractors, activities related to Stage 1.3 - Works, Commissioning and Monitoring of the Work Plan, in the following places: Headquarters of the municipality of Governador Valadares/MG, São Tome do Rio Doce, municipality of Tumiritinga/MG, Pedra Corrida, municipality of Periquito/MG and Headquarters of the municipality of Galiléia/MG.

On August 12, the City of Tumiritinga signed the Terms of Commitment for the locations of São Tomé do Rio Doce and the headquarters of Tumiritinga.
On August 3, 2022, the Renova Foundation presented to the expert team, in a videoconference meeting via Microsoft Teams, the update of the status summary of the projects and works of the 25 locations of Item 1 of the Priority Axis Court Decision No. 9.
On August 4th and 5th, 2022, the expert team carried out a technical visit to the works of the alternative water withdrawal (pipeline) at the headquarters of the municipality of Governador Valadares/MG, to evaluate and monitor the work execution activities carried out by the Renova Foundation and subcontractors, activities related to Stage 1.3, Works, Commissioning and Monitoring.
On August 9, 2022, the Renova Foundation presented to the expert team, in a videoconference meeting via Microsoft Teams, a summary of the history, the factual situation, the projects, the works and the water and sediment monitoring program in the region of the locality Ipaba do Paraíso, municipality of Santana do Paraíso/MG and the locality of Senhora da Penha, municipality of Fernandes Tourinho/MG.
On August 16, 2022, the expert team carried out a technical visit to the water treatment plant of the Ipaba do Paraíso locality, municipality of Santana do Paraíso/MG, to understand the history, factual and administrative situation, projects and works in progress, in development and carried out.
On August 17, 2022, the expert team carried out a technical visit to the water treatment plant of Senhora da Penha, municipality of Fernandes Tourinho/MG, to understand the history, factual and administrative situation, projects and works under development and carried out.
From August 16 to 19, 2022, the expert team carried out/will continue the expert technical visits with the beneficiaries registered in the water supply program of the Renova Foundation for Territory VII, which corresponds to the Quilombola Community of Degredo (Linhares/ ES) (ID 1260919781).
In August 2022, a transfer was made to the municipality of Santana do Paraíso, in the amount of R$ 43,500.00 referring to the Review of the Integrated Solid Waste Management Plan;

On July 5, 2022, the monthly technical session was held, where the update of the summary of the projects and works of the 25 locations of Item 1 of the Judicial Decision of Priority Axis No. 9 is presented.

On July 6th and 7th, 2022, the expert team carried out a technical visit to the works of the alternative water withdrawal (aqueduct) at the headquarters of the municipality of Governador Valadares/MG, to evaluate and monitor the work execution activities carried out by the Renova Foundation and subcontractors, activities related to Stage 1.3, Works, Commissioning and Monitoring.

On July 12, 2022, the technical session was held with a summary of the history, the factual situation, projects, works and the water and sediment monitoring program in the region of Boninsegna, municipality of Marilândia/ES.

On July 14, 2022, the expert team carried out a technical visit to the water treatment plant of the Boninsegna locality, municipality of Marilândia/ES, to understand the history, factual and administrative situation, projects and works under development and already carried out.

In reference to Territory VI, composed of the municipalities of Galiléia/MG and Governador Valadares/ES, on July 8, 2022, the expert team added the Expert Technical Reports R00 (ID 1200106249) referring to Stage 2.2 to the case file (Factful Situation) of Item 2 of the Judicial Decision.

On July 1, 2022, the Term of Commitment of the municipality of Baixo Guandu-ES was signed.

On July 19, 2022, the Term of Commitment of the town of Gesteira Mutirão-municipality of Barra Longa-MG was signed.

On June 2, 2022, the expert team carried out a technical visit to the water treatment plant of the Gesteira locality, municipality of Barra Longa/MG, to understand the history, factual and administrative situation, projects and works under development and already carried out.

On June 6, 2022, the Renova Foundation presented to the expert team, in a videoconference meeting via Microsoft Teams, the update of the status summary of the projects and works of the 25 locations of Item 1 of the Judicial Decision of Priority Axis No. 9.

On June 8th and 9th, 2022, the expert team carried out a technical visit to the works of the alternative water withdrawal (pipeline) at the headquarters of the municipality of Governador Valadares/MG, to evaluate and monitor the work execution activities carried out by the Renova Foundation and subcontractors, activities related to Stage 1.3, Works, Commissioning and Monitoring.

On June 20, 2022, the expert team added to the case file the Expert Technical Report of Stage 1.2 (Analysis of Schedules and Projects) referring to the headquartes of the municipality of Baixo Guandu/ES (ID 1154130763).

In reference to Territory V, composed of the municipalities of Baixo Guandu/ES and Colatina/ES, on June 8, 2022, the expert team added the Expert Technical Reports R00 (ID 1132910262) regarding Stage 2.2 to the case file (Factual Situation) of Item 2 of the Judicial Decision corresponding to the communities of Córrego Boa Esperança, Córrego Catita, Córrego da Piaba, Córrego do Lavra, Córrego Queixadão, Fazenda Fontenelle, Fazenda Porto Esperança, Fazenda Sapucaia, Ilha Bela Vista, Itapina, Maria Ortiz , Mascarenhas, Porto Belo and Santa Joana.

As discussed and agreed with the Municipality of Rio Doce, the Renova Foundation formalizes the agreement to demobilize the water truck, given that it is available, however, without demands in that location.

The Term of Commitment of the municipality of Marilândia/ES was signed.

On May 31, 2022, the Renova Foundation presented to the expert team, in a videoconference meeting via Microsoft Teams, a summary of the history, the factual situation, projects, works and the water and sediment monitoring program in the region of Gesteira, municipality of Barra Longa/MG.
On May 4, 2022, the expert team added to the case file the Supplementary Report - Clarification of the Stakeholders' Questions of Stage 1.2 (Analysis of Schedules and Projects) for the locality of São Tomé do Rio Doce, municipality of Tumiritinga/ MG (ID 1057863265).
"• On May 9, 2022, the Renova Foundation presented to the expert team, in a videoconference meeting via Microsoft Teams, the update of the status summary of the projects and works of the 25 locations of Item 1 of the Priority Axis Judicial Decision No. 9. "
On May 11th and 12th, 2022, the expert team carried out a technical visit to the works of the alternative water withdrawal (aqueduct) of the Headquarters of the municipality of Governador Valadares/MG, to evaluate and monitor the work and execution activities carried out by the Renova Foundation and subcontractors, activities related to Stage 1.3, Works, Commissioning and Monitoring.
In the weeks of May 2nd, 9th and 23rd, 2022, the expert team carried out expert technical visits to the locations and homes of the beneficiaries covered by the Renova Foundation's water supply program in Territory VI.
On May 20th, 2022, the expert team added Report No. 15 - Development of Water Quality Monitoring Activities (ID 1093544271) to the case file, informing the activities developed by the expert team for the start of water quality monitoring.

The expert team added the Expert Technical Reports (ID 1009718279) on April 1, Stage 2.2, Factual Situation, to Territory IV, corresponding to the communities of Córrego do Baixio, Pedra Ilha Lorena, Itueta Velha and Córrego Barra Provisoria, in the municipalities of Aimorés, Itueta and Resplendor/MG.
A technical session was held with AECOM on April 11 to present the summary of the history, the factual situation, projects, works and the water and sediment monitoring program in the headquarters region of the municipality of Baixo Guandu/ES and the locality Mascarenhas, municipality of Baixo Guandu/ES.
The Forensic team continued the technical expert visits on April 11, in the locations and homes of the beneficiaries covered by the Renova Foundation's water supply program in Territory V, which corresponds to the municipalities of Baixo Guandu and Colatina
The forensic team carried out a technical visit on April 13 at the water treatment plant at the Sede locality in the municipality of Baixo Guandu/ES and at the Mascarenhas locality, municipality of Baixo Guandu/ES, to understand the history, factual and administrative situation, projects and works under development and already carried out.
Completion of the flow and interference test of wells C-02 and C-03 at Cachoeira Escura on April 14th.
The expert team added Report No. 13 - Development of Water Quality Monitoring Activities (ID 1031876843) on April 18
On April 18, the drilling report for the Marilandia-Bonisegna well was delivered.
On April 18, the drilling report for the Baixo Guandu-Mascarenhas well was delivered.
On April 27, the water quality report of the well drilled in Baixo Guandu-Mascarenhas was delivered.
On April 27, the water quality report of the well drilled in Marilândia- Bonisegna was delivered

On March 7, 2022, the expert team carried out a technical visit to the water treatment plant of the São Tomé do Rio Doce locality, municipality of Tumiritinga/MG, to understand the history, factual and administrative situation, projects and works in progress, in development and that were already carried out.
On March 8, 2022, the expert team carried out a technical visit to the water treatment plant in Santo Antônio do Rio Doce, municipality of Aimorés/MG, to understand the history, factual and administrative situation, projects and works in progress, in development and thar were already carried out.
The drilling of the Baixo Guandu-Mascarenhas well was concluded on 03/16.
The drilling of the Marilândia- Boninsegna well was concluded on 03/19.

In the week of February 7, 2022, the forensic team carried out expert technical visits to the
locations and homes of the beneficiaries for the water supply that are included in the program of the
Renova Foundation of the municipalities of Ipaba, Caratinga, Santana do Paraíso that correspond to the
Territory III of Item 2 of the Judicial Decision.
In the week of February 14, 2022, the forensic team continued processing
of the information collected in the technical expert visits in the locations and homes of the beneficiaries of the water supply that are part of the Renova Foundation program for the municipalities of Ipaba,
Caratinga, Santana do Paraíso that correspond to Territory III of Item 2 of the Judicial Decision.
On the week of February 21, 2022, the expert team returned to activities related to Step 2.2, Factual Situation in Territory IV of Item 2 of the Judicial Decision. The location visited was Pedra Lorena, in the municipality of Aimorés.
On February 24, 2022, the Renova Foundation presented to the expert team, in a videoconference meeting via Microsoft Teams, the update of the summary of the status of the projects and works of the
25 locations of Item 1 of the Priority Axis Court Decision No. 9.

In the week of January 10th, 2022, the forensic team carried out expert technical visits in the localities of Ipaba and Caratinga, in the homes of beneficiaries served with water supply.

On the week of January 24th, 2022, the forensic team visited the following locations, in the homes of those assisted with water supply, Linhares, Ipaba, Caratinga, Santana do Paraíso, Aimorés, Itueta and Resplendor.

On January 26th, 2022, the expert team visited water treatment plants in the localities of Perpétuo Socorro (Cachoeira Escura), municipality of Belo Oriente/MG, and São Vitor, municipality of Governador Valadares/MG, to understand the history, situation factual and administrative, projects and works in progress and already carried out.

On January 27, 2022, the expert team carried out a technical visit to the works in progress of the alternative water withdrawal (pipeline) at the headquarters of Governador Valadares/MG.

On January 31st, the expert team carried out a technical visit to the water treatment system in the town of Regência, municipality of Linhares.

In 2021, according to the expertise development letter (annex) of Axis 9, the following locations were visited:
Item 01 - Headquarters, municipality of Galileia; Headquarters, municipality of Resplendor; Headquarters, municipality of Governador Valadares; Headquarters, municipality of Linhares, Headquarters, municipality of Itueta; Pedra Corrida, municipality of Periquito.
Item 02 - Bento Rodrigues, municipality of Mariana; Ponte do Gama, municipality of Mariana; Santana do Deserto, municipality of Rio Doce; Camões, municipality of Sem-Peixe; Headquarters, municipality of Barra Longa, Gesteira, municipality of Barra Longa; Community of Entre Rios, municipality of Linhares; Community of Areal, municipality of Linhares; Community of Povoação, municipality of Linhares; Community of Papagaio, municipality of Linhares; Community of Bebedouro, municipality of Linhares; Baixada do Coronel Community, municipality of Ipaba; Baixada do Coronel community, municipality of Caratinga.

Profiling, pumping and flow test of the Ponte do Gama well.

As a result of the judicialization of the Program, technical visits were carried out by Axis 9 Expertise in the locations of Santana do Deserto, Gesteira Mutirão, Pedras, Ponte do Gama, Pedra Corrida, Itueta and Baixada do Coronel Roberto (Ipaba and Caratinga).
Start of interference tests in the flow of wells C1 and C2 of COPASA in Itueta.

With the PG32 judicialization process in regards to Priority Axis No. 9, most of the actions inherent to TTAC Clause 171 are conditioned to the decision of the Judge of the 12th Federal Court of Belo Horizonte, thus impacting the schedule filed with the CIF in November 2019.

Regarding the PG32 judicialization process, Priority Axis No. 9, most of the actions inherent to TTAC Clause 171 are conditioned to the decision of the Judge of the 12th Federal Court of Belo Horizonte, thus impacting the schedule filed with the CIF in November 2019.

There were no relevant facts in february.

There were no relevant facts this month

Judicialization of the program in the context of priority axis 9 of the public Civil action at the 12th Federal Civil and Agrarian Court of the judicial section of Minas Gerais. Many of the scopes of interventions in the localities are being challenged in court, and therefore projects and construction works have been paralyzed. An expert report and subsequent court decision are expected to review the scope of the works and the schedule of implementation of construction works.

Start of the water extraction and piping projects for the new well in Regência / ES.

Completion of field work to refine the list of recipients of water supply through water trucks and delivery of mineral water.

Manufacturing of the Doce river water extraction ferry completed -Resplendor / MG.

Resumption of improvement works at the Vila Isa Water Treatment Plant, in Governador Valadares/MG.
Judicialization of Priority Axis nº 9 of the Program in a Public Civil Action of the 12th Federal Civil and Agrarian Court of the Judicial Section of Minas Gerais. Many of the interventions in scope in the districts are being questioned in court and, therefore, projects and works have been suspended. The report of the inspection and a subsequent judicial decision are awaited to review the scope of the works and the schedule for implementing the works.
Completion of the basic design of the water withdrawal, adduction and treatment system in Itueta/MG.
Completion of the water quality analysis of the new Regencia well, district of Linhares/ES.

Tubular well drilling in Regência, Linhares district / ES. Water quality and flow studies will be carried out to verify the viability of the well as a supply solution for the area;
* Start of the works on the foundation of the water capture system on the Corrente Grande River water pipeline, in
Governador Valadares / MG;
* Resumption of works on the Alternative Water Collection system in the district of São Vítor, Governador Valadares / MG;
* Completion of the basic project of the alternative water collection system in the district of Cachoeira Escura,
in Belo Oriente / MG;
* Completion of the detailed project of the main and alternative water collection system, and water treatment system in the district of Pedras, Mariana / MG;
* Completion of the detailed project for the new Baixo Guandu/ES Water Treatment Plant

• Resumption of the construction works for alternative water withdrawal in Pedra Corrida, Periquito/MG district. Commencement of paving works for the pipeline ditch that connects the well to the local water treatment plant;
• Resumption of the works for relocation of the transmission line of the Corrente Grande River pipeline in Governador Valadares/MG.
• Kickoff of the works to recover the paving of the North access road in Resplendor/MG.
• Completion of the basic project for the new water treatment plant and main water withdrawal in Senhora da Penha, district of Fernandes Tourinho/MG.
• Completion of the basic project for the new water treatment plant in Baixo Guandu/ES.
• Supplied 23,548 m³ of water to the population of Resplendor/MG through the operation of wells C01 and C02 as the definitive solution for alternative water withdrawal in the municipality.
• Land release by the municipal government of Tumiritinga/MG in the area of Praia do Jao beach to implement the works of the Program in the district.
• Judicialization of the program for Priority Axis No. 9 of the Public Civil Action of the 12th Federal Civil and Agrarian Court of the Judicial Section of Minas Gerais. Many of the interventions in scope in the districts are being questioned in court and, therefore, projects and works have been suspended. The inspection report and a subsequent judicial decision are awaited to review the scope of the works and the schedule for implementing the works.
• Suspension of the program's non-priority works as a preventive measure in the midst of the COVID-19 pandemic, in compliance with the Renova Foundation's governance guidelines and the recommendations of health entities.

• Approval by the Renova Foundation’s Situation Room to resume the program’s prioritized works in Governador Valadares, Periquito, Resplendor, and Itueta, in the state of Minas Gerais, meeting all security measures concerning COVID-19.
• Resumption of earthworks in the water withdrawal area of the main pipeline of the Corrente Grande River, in Governador Valadares (MG).
• Resumption of the works of the main Corrente Grande River pipeline crossing the BR-381 highway in Governador Valadares (MG).
• Contracted the executing company for the drilling of the tubular well that will serve as the main water withdrawal source for the town of Regencia in the district of Linhares (ES).
• Completion of the executive project for the new water treatment station and main water withdrawal in Sao Tome do Rio Doce, Tumiritinga district (MG).
• Response protocol by the maintainers, in compliance with Item 1.2 of Priority Axis No.9 (Water Supply for Human Consumption) of the Public Civil Action at the 12th Federal Civil and Agrarian Court of the Judicial Section of Minas Gerais, regarding the items to be considered in the inspection.
• Judicialization of the program in the context of Priority Axis No.9 of the Public Civil Action of the 12th Federal Civil and Agrarian Court of the Judicial Section of Minas Gerais. Many of the interventions in scope in the districts are being questioned in court and, therefore, projects and works have been suspended. The report of the inspection and a subsequent judicial decision are being awaited to review the scope of the works and the schedule for implementing the works.
• Suspended the program's non-priority works as a preventive measure amidst the COVID-19 pandemic, in compliance with the governance guidelines of the Renova Foundation and recommendations of health entities.

• Completing the assisted operation period for the new Water Supply system for Galileia, Minas Gerais. The system includes 4 tubular wells and one new WTP equipped with a Waste Treatment Unit (WTU).
• Increasing operating hours for the C01 and C02 wells from 9 to 13 per day, in Resplendor, Minas Gerais, reducing the municipality's dependence upon emergency supply from water tank trucks.
• Response protocol in compliance with Item 1 of Priority Axis No. 9 (Water Supply for Human Consumption) of the Public Civil Action by the maintainers at the 12th Federal Civil and Agrarian Court of the Judicial Section of Minas Gerais.
• Completing the detailed project for the new Water Supply system for Boninsegna, district of Marilandia, Espirito Santo.
• Completing the basic project for the main water withdrawal and new WTP in Sao Tome do Rio Doce, Tumiritinga district, Minas Gerais.
• Suspending the Program's works as a preventive measure during the COVID-19 pandemic, in compliance with the governance guidelines of the Renova Foundation and the recommendations of health entities.

• Obtained the assessment reports for land regularization for the construction works of the new Water Treatment Plant, Water Withdrawal from the Doce River and Pipeline Interconnection with the existing well in Sao Tome do Rio Doce/MG, Tumiritinga/MG district.
• Obtained an approval certificate for underground water withdrawal from the well in Sao Tome do Rio Doce/MG, district of Tumiritinga/MG.
• Commissioned wells C01 and C02 and the Water Softening System in Resplendor/MG.
• Partial delivery of hives and filter beds to the Autonomous Water and Sewage Service of Linhares/ES.
• Suspension of the Program's works as a preventive measure amid the COVID-19 pandemic, in compliance with the governance guidelines of the Renova Foundation and the recommendations of health entities.
• Plans for the resumption of each work site were presented and are under evaluation by the board of director of the Renova Foundation.

• Beginning of works to renovate the water pipeline and adapt the Gesteira reservoir in the district of Barra Longa/MG.
• Start of operation of wells C01 and C02 and the softening system in Resplendor/MG, with the acceptance by COPASA (Sanitation Company of Minas Gerais) of the system as an alternative water withdrawal solution for the municipality.
• Increase in the percentage of water blending in Regencia WTP (Water Treatment Plant) in the district of Linhares/ES to 80% of water from the tubular well and 20% of water supplied by water tank trucks.
• Completion of the works to adapt the water withdrawal intake at the Nova Lagoon in Lagoa in Linhares/ES.
• Obtaining the authorization form from the owner to access the area in the district of Linhares/ES where the new well for Regencia will be drilled.
• Obtaining the municipal environmental license for the works of the pipeline and water withdrawal from the Guandu River in Baixo Guandu/ES and of the treated water pipeline, which links the main WTP to the district of Mascarenhas.
• Suspension of the Program's works as a preventive measure in the midst of the COVID-19 pandemic, in compliance with the governance guidelines of the Renova Foundation and the recommendations of health entities.

• Delivery of the following to the Autonomous Water Sanitation Service (SAAE) and municipality of Galileia/MG: the Galileia treatment system, comprising the new Water Treatment Plant (WTP), Wastewater Treatment Unit (WWTU), water pipeline, treated water reservoir and alternative water withdrawal (four wells, P1, P2, P3 and P4).
• Completion of the conceptual project of the WWTU of Linhares/ES.
• Completion of the basic project for the main water withdrawal and new WTP in Sao Tome do Rio Doce, Tumiritinga district/MG.
• Compliance with item 3 of resolution 379: “The Renova Foundation proceeds to collect and properly dispose of the coagulant product supplied, which has expired, from the WTP IV reservoirs in Colatina/ES”.
• Conducting geophysical studies in the town of Ipaba do Paraiso, district of Santana do Paraiso/MG.
• Increase in the percentage of water blending in the Regencia WTP, district of Linhares/ES, to 70% of water from the tubular well and 30% of treated water supplied by water trucks.
• Progress in the works to adapt the main water withdrawal pipelines of the Nova Lagoon, in Linhares/ES.
• Progress in the improvement works at the WTP of Vila Isa, in Governador Valadares/MG.
• Progress in the main pipeline works and cleaning of the water withdrawal area in the Corrente Grande River, in Governador Valadares/MG.
• Progress in the improvement works at the WTP and interconnection with the Pedra Corrida well, in the district of Periquito/MG.

• Completion of the executive project for improvements to the Water Treatment Plant of Linhares/ES.
• Completion of the executive project for the Mascarenhas treated water pipeline, which links the district to the Water Treatment Plant of Baixo Guandu/ES.
• Delivery of two 50-hp pumps for the Autonomous Water and Sewage Service of Linhares/ES.
• Issuance of the declaration of public utility for the Corrente Grande River pipeline by the Municipal Office of Governador Valadares/MG.
• Beginning of the works to adapt the main pipelines for water withdrawal from the Nova Lagoon, in Linhares/ES.
• Increase in water blending in the Regencia water treatment plant, district of Linhares/ES. Sixty percent of the local demand is being met by using the recovered tubular well and forty percent by water trucks, ensuring greater security of the local water supply.
• Progress in the improvement works at the WTP of Vila Isa, in Governador Valadares/MG.
• Progress in the main pipeline works and cleaning of the water withdrawal area in the Corrente Grande River, of the Governador Valadares/MG pipeline.
• Progress in the works to improve the WTP and interconnection with the Pedra Corrida well, in the district of Periquito/MG.

Mid Doce River Territory
Completion of the conceptual project for new interventions to improve the Barroso Creek Dam in Resplendor/ES.
Completion of the adjustment works and initiation of water withdrawal operation at the Barroso Creek in Resplendor/MG.
Completion of the executive improvement project at the Water Treatment Plant of Resplendor/MG.
Works to improve the water supply system in Resplendor/MG have not been completed. Cause: Adjustments in the high voltage network, which required an unforeseen change of the name on the energy bill of COPASA (Sanitation Company of Minas Gerais) to the Renova Foundation. Countermeasure: Receive documentation from the energy provider in order to start the power structuring works, scheduled for December 2019. Completion of works scheduled for February 2020.
The well interconnection works in Boninsegna, district of Marilandia/ES, scheduled for 2019, have not been completed. Cause: Scope change in relation to the initial design of the local water supply solution of the district. Countermeasure: Develop projects by February 2020 according to the new scope defined for the location.
General
Submission of the revised document for the definition of the Water Supply Systems Improvement Program to the Interfederative Committee (CIF) and Technical Board (CT-SHQA) by means of letter OFI.NII.092019.7938, contemplating the proposals and considerations presented in Technical Note No. 48 of CT-SHQA, in compliance with CIF Resolution No. 315, of September 27, 2019.
The drilling and recovery services for all tubular wells that will be used for alternative water withdrawal to the Doce River, in the districts contemplated by Clause 171, scheduled for 2019, have not been completed in Camargos, Mariana/MG district, and Ipaba do Paraiso, district of Santana do Paraiso/ MG. Cause: Scope change in relation to the initial design of water supply solutions. Countermeasures: Obtain drilling authorization for the well in Camargos, by February 2020, and perform geophysical surveying to define the locations on the 5 properties in Ipaba do Paraiso for drilling the wells, by January 2020.
Hydrogeological studies in districts along the Doce River Basin and coastal zone, scheduled for 2019, have not been completed. Cause: Change in program responsible for hydrogeological studies. Countermeasure: Transfer responsibility for hydrogeological studies to Program 023 - Tailings Management; transfer completed in 2019.
Not all works in all districts provided for in Clause 171, scheduled for 2019, have begun. Cause: Delay in the elaboration of projects and, eventually, in land and licensing processes. Countermeasure: Hire new architects to prepare the projects for the districts served by the Program; new hires completed in September and November 2019.
Development, by the Renova Foundation, and approval, by the municipal governments and operators, of all basic engineering projects in all districts provided for in Clause 171, scheduled for 2019, have not been completed. Cause: Delay in the preparation of basic projects due to the lack of resources of the architecture companies. Countermeasure: Hire new architecture companies to prepare the projects for the locations served by the Program; hire completed in September and November 2019.

• Completion of the executive project of improvements to the Water Treatment Plant of Resplendor/MG.
• Completion of maintenance of 6 pumps at the Autonomous Water and Sewage Service of Linhares/ES.
• Completion of the executive project of Improvements to the treated water pump stations in Cachoeira Escura, Belo Oriente district/MG.
• Completion of the Executive Project of Alternative Water Withdrawal and Well Treatment System of Sao Vitor, Governador Valadares/MG district.
• Completion of the executive project for Improvements to the Central WTP of Governador Valadares/MG.
• Completion of works at the Main Water Withdrawal Station of Pedra Corrida, district of Periquito/MG.
• Initiation of assisted operation of the new WTP and of the Waste Treatment Unit of Galileia/MG to guarantee system functionality.
• Continuation of contracting process of the company that will execute the improvement works to the Guandu River Pipeline, Repowering of the Mascarenhas Treated Water Pump Station and Pipeline in Baixo Guandu/ES. Proposals were received from interested companies and the contracting process is expected to be completed by February/2020.
• Initiation of procedures for land regularization and environmental licensing of the works for adaptation of the Guandu River Pipeline and Mascarenhas Treated Water Pipeline, Baixo Guandu District/ES.
• Progress has been made with the improvement works to the WTP and Alternative Water Withdrawal of Pedra Corrida, district of Periquito/MG.
• Progress has been made with the construction of the urban stretch and the tunnel liner of the Corrente Grande River Pipeline in Governador Valadares/MG.
• Progress has been made with the improvements works to the WTP and Alternative Water Withdrawal of Sao Vitor in Governador Valadares/MG.

• Completion of the first five kilometers of the Corrente Grande River pipeline in Governador Valadares (MG).
• Transfer of funds for the infrastructure of the conceptual improvement project of the Barroso Stream catchment dam in Resplendor (ES).
• Conclusion of the pipeline improvement works to supply the water tank trucks in the WTP area in Mascarenhas, Baixo Guandu district (ES). Improvements will increase water supply agility and capacity for the community.
• Approval of the detailed projects of WTP improvements in Tumiritinga (MG) by COPASA.
• Maintenance and installation of two pumps for water withdrawal in the Pequeno River, at SAAE of Linhares (ES).
• Initiation of company contracting to carry out the works for adjusting the Guandu River pipeline and repowering the Elevated Water Storage Station, in Baixo Guandu/ES, and the pipeline for treated water in the Mascarenhas district.
• Progress in the WTP improvement works and urbanization of the well and the alternative water withdrawal pipeline of Pedra Corrida, district of Periquito (MG).
• Completion of the WTP Improvement works and main water withdrawal of Sao Vitor, Governador Valadares district (MG).

• Conclusion of the urbanization works and interconnection of the wells in Galileia (MG), completing the alternative water withdrawal works in the municipality.
• Completion of improvement works at the WTP of Galileia (MG). Improvements include the installation of a compact WTP capable of handling 25 liters per second, the construction of a waste treatment unit (WWTU), the revitalization of the treated water reservoir, among others.
• Obtained approval from the environmental agency for water withdrawal from wells 01 and 02 in Galileia (MG).
• Completion of urbanization works at WTP Recanto dos Sonhos, in Governador Valadares (MG).
• Transaction of funds to the infrastructure area of the executive project for adjustments to the alternative water withdrawal of Lagoa Nova, in Linhares (ES).
• Progress was made in improvement works at the Pedra Corrida WTP, Sao Vitor WTP and water pipeline of Governador Valadares (MG).
• The revision of the definition of the program was filed with CIF, contemplating the proposals and considerations presented in CT-SHQA Technical Note 48, in compliance with CIF Resolution 315, of September 27, 2019.

• APRO Approval for land regularization of the area used for the installation of the water pipelines and elevated water storage station of water withdrawn from the Pancas River, an alternative water withdrawal solution in Colatina (ES).
• Completion of detailed projects of the Individual Water Supply Systems of Ipaba do Paraiso, Santana do Paraiso district (MG).
• Completion of the alignment works and beginning of the water withdrawal operation in the Barroso stream, in Resplendor (MG). The delivery will reduce the municipality's dependence on water supply by water tank trucks.
• Execution of paving works and improvements in the Recanto dos Sonhos and Sao Vitor WTPs in Governador Valadares (MG) and the Pedra Corrida WTP in Periquito (MG).
• Electromechanical assembly and installation of water withdrawal unit in the Doce River in Galileia (MG).
• Excavation of the stretch under the BR-381 (Tunnel Liner) of the water withdrawal pipeline in the Corrente Grande River, in Governador Valadares (MG).

• Mobilization of the team and initiation of improvements works at the WTP of Pedra Corrida, district of Periquito/MG. Improvements include repairs to the main inlet pipeline, WTP structure renovations, acquisition of new metering pumps and construction of a Waste Treatment Unit.
• Delivery of the Infrastructure of the executive improvement projects at the WTP and water withdrawal from the Doce River in Tumiritinga/MG and alternative water withdrawal in Pedra Corrida (Periquito/MG).
• Completion of the assembly of the Water Softening System in the WTP of Resplendor/MG.
• Assembly of the contact tank and installation of the hydro cyclone, as part of the improvement works at the WTP of Galileia/MG.
• Conducting repair and cleaning works at the Pequeno River Barrier in Linhares/ES.
• Construction of the pipeline at the Railroad stretch of the Corrente Grande River pipeline of Governador Valadares/MG and approval of the revision of the environmental licenses for the new urban layout.

• Completion of the interconnection of wells C01 and C02 with the WTP of Resplendor (MG).
• Completion of executive projects for improvements to the WTP and the main water withdrawal of Baixo Guandu (ES) and improvements to the Gesteira reservoir and water pipeline (MG).
• Obtained DAIA for plant suppression and PPA intervention for the execution of the Corrente Grande river pipeline, in Governador Valadares (MG).
• Obtained the results of the water quality reports and flow test of Well 2 in Pedras (MG), proving the well's capacity to meet the local water withdrawal demand.
• Execution of access road improvement works at Recanto dos Sonhos and Sao Vitor WTPs and electromechanical assembly of the WTP of Galileia (MG).
• Works to improve the construction site and cleaning of the Reno Mattress in the Pequeno River Barrier, in Linhares (ES).

• Recovery of wells in Cachoeira Escura, Belo Oriente district, and in Sao Tome do Rio Doce, Tumiritinga district (MG), as an alternative solution for water withdrawal for these districts.
• Completion of the executive projects for improving the WTPs of Galileia, Pedra Corrida, Periquito district, WTP Santa Rita and Recanto dos Sonhos and Sao Vitor, in Governador Valadares (MG).
• Completion of executive projects for improving the main water withdrawal of Pedra Corrida, district of Periquito, and of Sao Vitor, district of Governador Valadares (MG).
• Completion of the works of the Casa de Quimica and beginning of the electromechanical installation of the WTP of Galileia.
• Initiation of works of the Liner Tunnel that crosses the BR-381 highway of the Corrente Grande river pipeline in Governador Valadares.

• 50% of water from the WTP in Regencia (MG) is used and blended with 50% of water from the water tank trucks, securing the water supply of the municipality.
• Approval by the CIF of the water supply project requested by the municipality of Aimores (MG).
• Completion of the conceptual projects for the water withdrawal and WTPs of Pedras and Camargos, districts of Mariana (MG), and Barreto, district of Barra Longa (MG).
• Drilling of Well 02 in Pedras, district of Mariana (MG).
• Inauguration of the water pipeline in the elevated stretch (km 28.6 to 31.5) and WTP Santa Rita branch (km 0.00 to 0.14) for water withdrawal from the Corrente Grande River in Governador Valadares (MG).
• Assembly and welding of the electrical ducts structure and completion of concrete floors for the drainage box and pump in the WTP of Cachoeira Escura, district of Belo Oriente (MG).
• Conclusion of the concrete floors of the elevated stations and covering of the drainage pipe in the WTP of Galileia (MG).

Completion of the Conceptual Project for Improvements in the Water Supply System (STA) of Pedras, Barreto and Camargos.
Completion of the STA assembly in the WTP in Resplendor (MG).
Interconnection of the wells C01 and C02 to the reservoir of Resplendor (MG).
Completion of the main water pipeline of Entre Rios, in Linhares (ES).
Completion of the installation of guardrails at the WTP Vila Isa in Governador Valadares (MG).
Completion of the concrete base for the new WTP in Galileia (MG).

Alternative Water Withdrawal
Completion of the reopening, recovery and screening services in the existing tubular well in Sao Vitor, district of Governador Valadares. The Renova Foundation is awaiting the report with the results of the well recovery to determine its feasibility.
Covering (filled with cement) of the tubular well drilled in Pedras, district of Mariana, due to the unavailability of water.
Improvements to Water Supply Systems
Delivery and installation of the milk cooler tank for rural landowners in Gesteira, district of Barra Longa, based on the agreement made by the land ownership team of the Renova Foundation. Furthermore, conclusion of the works to make the area where the water pipeline will be built, together with the owner, more accessible.
The municipality of Fernandes Tourinho accepted the proposal for improvement of the Water Treatment System (SAA) in the district of Senhora da Penha, including the definition of the main solution for water withdrawal and installation of a Water Treatment Plant in the Doce River.

Alternative water withdrawal
Covering of tubular well drilled in Senhora da Penha, district of Fernandes Tourinho, due to the legal norm of IGAM.
Instrumentation and assembly of the electrical panels of the four existing tubular wells in Galilee, which will be used for alternative water withdrawal.
Delivery of the first shipment of pipes for the Governador Valadares pipeline.
The report with analysis of the water quality of the new tubular well drilled at the request of the SAAE in Regencia, district of Linhares, was made available.
Agreement with the SAAE of Linhares for the cancelation of 50% of the water tank trucks, due to the results of the blended water analysis - water of the WTP in Regencia blended with the water supplied by the trucks.
Improvements to Water Supply Systems
On 12/14/18, was made available by COPASA the technical statement on the hydrogeological potential for service regarding the water supply system to be installed in Alpercata, with the conclusion that only the Doce River presents “the right size for water withdrawal by pipeline", and there is no possibility of using underground sources due to quali-quantitative water problems in relation to surface water sources.
Continuation of the basic and executive engineering projects for the districts of TTAC clause 171.

Alternative water withdrawal
Drilling of a new tubular well in Regencia, district of Linhares.
Interference tests in wells in Pedra Corrida, district of Periquito.
Improvements to Water Supply Systems
Alteration to the main water withdrawal solution in Senhora da Penha, district of Fernandes Tourinho, due to the poor water quality of the drilled tubular well. A meeting has been scheduled for the definition of a new water withdrawal source.

Alternative Water Withdrawal
On 10/02, the following actions were carried out: cleaning, disinfection services, a new test for pumping and collecting water from the Copasa tubular well in Tumiritinga - Sede, which will be used as an alternative water withdrawal source in the municipality.
On 10/26, the following services were completed: screening, cleaning and disinfection and recovery of the tubular well in Pedra Corrida, district of Periquito.
On 10/04, performed the services to test the pumping and water collection in the tubular well drilled in Senhora da Penha, district of Fernandes Tourinho. The results will assess the feasibility of the operation of this well.
Improvements to the Water Supply System
On 10/19, the recovery works at the elevated reservoir of the WTP of Galileia were completed.
On 10/02, the Wastewater Treatment Units of the WTPs in Governador Valadares were approved by SAAE.
A meeting was held with the community and territory leaders in Resplendor to engage with the population regarding the resumption of water supply from the Doce River and acceptance of the alternative water withdrawal system in Resplendor and Itueta.

Alternative Water Withdrawal
The dry well was closed in Santo Antonio do Rio Doce, municipality of Aimores. The well had been drilled to meet alternative water withdrawal. It is noteworthy that there is still a tubular well, whose flow is sufficient to serve the municipality as an alternative water withdrawal source, but it is not used because the population is objecting.
The Renova Foundation carried out the drilling of the tubular well in the district of Senhora da Penha, in the municipality of Fernandes Tourinho, to attend to the delivery of an alternative water withdrawal source.
Conversations with the community about the initiation of the works in the Ramifications of the Pipeline (Central, Vila Isa and Sta Rita WTP), and Preliminary Inspection services;

Improvements to Water Supply Systems
The September campaign on water collection at the exit of WTP in Regencia, Linhares municipality, started in April 2018, with weekly frequency.
A survey was carried out by the Technical Board for Water Security and Water Quality, and Ernst & Young, in the districts of TTAC clause 171, to verify the progress of the actions according to the time frames of PG 32.

Sent to CIF and CTSHQA are the Acceleration Plan for deliveries of the Water Supply Systems Improvement Program (PG32) to meet Resolution 185.

Alternative Water Withdrawal

The Renova Foundation cleaned and disinfected the four tubular wells operated by SAAE in Galilee and performed new pumping tests. These wells are the alternative water collection of the municipality.
The Renova Foundation completed the installation of a new internal coating in the tubular well connected to the WTP of the district, aiming to improve the quality of the water withdrawn. After that, they were cleaned and disinfected, and new pumping tests were performed. It is worth remembering that this well is part of the alternative water withdrawal system in the district.

The executive projects of the water pipeline works in Governador Valadares were submitted for formal consent by SAAE and the Municipal Government and after that were sent to the Technical Board CTSHQA to be handled according to the TTAC.

Improvements to Water Supply Systems

The Renova Foundation cleaned and disinfected the tubular wells of Copasa, in Itueta, and did new pumping and instrument tests to improve the water production. These wells help supply the district in addition to the water supply by means of a water tank trucks provided by the Renova Foundation. It is worth remembering that the alternative water withdrawal defined for Itueta and agreed with the Municipal Government and Copasa will take place by means of withdrawing water from the Manhuacu River and that the main withdrawal will continue to be from the Doce River. Sent to CIF and CTSHQA were the detailed and revised time frames of the actions of the Water Supply Systems Improvement Program (PG32) to meet Resolution 185.

The Coordination of the Technical Board of Water Security and Quality informed, in a meeting held on July 17, 2018, that the articulations for the resumption are occurring with the Staff of the Presidency of the Republic of the Government of Minas Gerais and of the Prosecution Service of Minas Gerais.

A proposal was submitted by COPASA for the measuring the feasibility, by the Renova Foundation, of the operation of three wells which were already drilled by the company. The wells will be used for alternative water collection, as defined by the program. Flow tests and water quality analyses are scheduled in order to develop the basic and executive projects.

Maintenance was performed on the power systems, connections and seals, dosers and tubular well of the water treatment system to normalize the constant interruptions in the community’s water supply. For next month, a technical analysis of the spring by PG 32 is scheduled, as requested by the community as an optional water source.

Construction of the Governador Valadares pipeline began, starting with the plant suppression service in the Figueirinha stream.

Initiated the studies to elaborate the definitive water supply projects for Degredo, Entre Rios and Areal de Regencia.

This month, the following activities were carried out:

● Alternative water withdrawal in Gesteira (district of Barra Longa): optical screening, cleaning and disinfection, besides the new pumping test in the Beira Rio well;
● Galilee (center): optical screening of the four tubular wells;
● Governador Valadares (center): due to land issues, the completion of the executive project of the Corrente Grande River pipeline is still pending. The activity is expected to be completed in July;
● Sao Vítor (District of Governador Valadares): optical screening of the tubular well;
● Paracatu de Baixo (district of Mariana): issued a geophysical report with results of the analyses carried out in May. However, the results were not satisfactory for the location were the tubular well was supposed to be drilled. Therefore, new studies will be carried out in different areas to guarantee the drilling of this well;
● Resplendor (center): the services to connect the wells are underway and activities are expected to be completed in August;
● Ipaba do Paraiso (district of Santana do Paraiso): a reanalysis of the registrations of the families to be attended;
● Improvements to water treatment systems Galilee (center): the renovation of the treated water reservoir is under way;
● Governador Valadares (center): topography of the Central and Santa Rita Water Treatment Plants (WTPs), which are to receive improvements. In addition, the final version of the conceptual designs of the Wastewater Treatment Units (WWTUs) of
the WTPs was completed. The projects are expected to be delivered to the Autonomous Water Sanitation Service (SAAE) in July;
● Sao Vitor (Governador Valadares district): the final version of the conceptual projects of the WWTUs of the water treatment plants has been completed. The projects are expected to be delivered to the SAAE in July;
● Ipaba do Paraiso (district of Santana do Paraiso): a reanalysis of the registers of the families to be attended.

The response to the Prosecution Service’s report regarding a study on the treated water from the São Tomé do Rio Doce tubular well in the municipality of Tumiritinga was prepared and filed. The document stated water quality compliance after the salinity deminerator treatment.

The update on the Program’s macro-chart was also presented to the Technical Board of Water Security and Quality in a monthly ordinary meeting.

The reference term for contracting studies draft has also been completed. Those studies will identify the contamination of aquifers and the location of tubular wells and be used for hydrogeological dynamics.

In addition, a monthly report was issued listing the actions to improve water supply systems that were carried out throughout March and April 2018.

Five tubular wells that will not be used for public supply were also capped. The well-capping form that the contracted company, Hidropocos, filled out will be sent to IGAM by the licensing department.

During a budget review meeting with the maintainers’ socio-environmental committee, the relocation in the program’s budget was justified. On this occasion, the teams in charge of this explained the need to add tankers and to change the scope of the Governador Valadares pipeline, as requested by Copasa and the city hall. The committee is yet to issue its decision on the approval of this justification.

After alignment between Copasa, the Municipal Government and Alliance Consortium, it was decided that works will be carried out in Resplendor for the interconnection of wells C1 and C2, as well as the renovation of the elevated water storage station, as an alternative form of water collection. The activities to interconnect the wells are expected to be completed by August 31, 2018.

The company QF Pesquisa Mineral carried out a geophysical service to locate a well to be drilled to meet the need for alternative water withdrawal in the town of Senhora da Penha, in the municipality of Fernandes Tourinho. The activity was completed on April 20, 2018.

This same company also began the works to revitalize the reservoir of the water treatment plant of Galileia, an activity that is supervised by the construction department. Completion of this work is scheduled for August 20, 2018.

Also carried out was the initial mobilization of the contract with the contractor for the execution of drilling, recovery and buffering services for tubular wells. The goal is to complete all services in the tubular wells within two years.

The tubular well of the Regencia district, located in the municipality of Linhares, was cleaned and optical probing was performed.

In Ponte do Gama, the contractor Itapocos drilled a well. A flow test was also performed, and samples were analyzed to identify the quality of the water, an activity that helps determine what treatment system should be used for it.

The program team also delivered a water treatment plant to the town of Regencia, in the municipality of Linhares, after signing the term of delivery and conditions by the operator of the water supply system (SAAE). The delivery is in compliance with the conditions established during the assessment of the WTP.

Conclusion and submission of the conceptual studies and basic projects related to water supply systems.

Completion of hiring process of drilling company for wells.

The Water Treatment Plant Project of the Bonisegna district (municipality of Marilandia, ES) was approved by the Marilandia Autonomous Water and Sewage Service (SAAE).

The final version of the Surface and Groundwater Capacity Studies report was submitted to the Interfederative Committee (CIF) and the Technical Board of Water Security and Quality for the construction of alternative water supply systems. Geophysical field surveys were conducted and reports were drafted for the resettlement of Gesteira and for the districts of Barreto and Camargos, in Minas Gerais.

The Scope Statement and Project Premises of the Water Supply System of Ponte do Gama (Sub-district of Camargos) were filed with the SAAE of Mariana (MG). On that same day, a meeting was held at the State Department of Environment and Sustainable Development (SEMAD) with representatives of the institution, State Water Management Institute of Minas Gerais (IGAM), Chief of Staff of the Execute Branch of the State of Minas Gerais, State Health Secretariat, COPASA and the Renova Foundation, for discussing the water withdrawal in Resplendor (MG).
Field visits were made by the company ESSE Engineering for the development of the basic Water Supply Systems projects for Pedras, Camargos and Barreto.

The Scope Statements and Project Premises (DEPPs) for the districts of Pedras, Camargos and Barreto were finalized, while the slowing system in tubular wells that were built in Sao Tome do Rio Doce (MG) is being installed.

A meeting was held with the company Hidropocos to start the drilling of wells.

In support of the Reconstruction of Villages Program, two wells were built in the area selected for the resettlement of Bento Rodrigues (MG) and the drilling of a tubular well in the area that will house the new village of Paracatu de Baixo (MG). A water availability analysis report was also prepared, evaluating 4 scenarios for the resettlement in Gesteira (MG), the geophysical field survey and the report of the host area of Paracatu de Baixo (MG).

The Renova Foundation received from the company Tecnosult the assessment results of the Central ETA of Governador Valadares and ETAs of Recanto dos Sonhos and Vila Isa. Proposals for improvements to the facilities were received and are being evaluated.

Field visits were carried out to prepare the Work Plan related to the Assessments of the Residue Treatment Units, with the attendance of the operators, technicians of the Renova Foundation and the company Tractebel.

In Ipatinga (MG), a meeting with Copasa discussed the status of the water supply systems in Resplendor and Itueta, in Minas Gerais. The solution for the public water supply of Resplendor, whose population is still being supplied by water tank trucks, was also on the agenda of the meeting at Semad. IGAM and Copasa also participated in the meeting.

The program concluded the assessment of water treatment conditions in the Ipaba do Paraiso neighborhood, in Santana do Paraiso (MG). At the Water Treatment Plant (ETA) of Regencia (ES), two operators received training related to water treatment.

The technicians of the program supported the completion of the rehabilitation and instrumentation of the tubular well, located in the Krenak indigenous territory, its operation and maintenance will be managed by the Special Secretariat of Indigenous Health (Sesai) of the Ministry of Health.

In a meeting with the Sanitation Company of Minas Gerais (Copasa), the assessment of the ETA of Itueta (MG) was validated. In that meeting, the Manhuacu River was also validated as an alternative spring.

At the Water Treatment Plant (ETA) of Regencia, district of Linhares (ES), an operator was trained, and a biodigester and a new residues treatment unit were installed. In Cachoeira Escura, the ETA assessment was validated by a concessionaire.

Between November 6 and 10, the Technical Board of Water Security and Quality (CTSHQA) carried out the first stage of an inspection at the water supply systems of Minas Gerais, with the support of the Renova Foundation team. The second stage took place between November 20 and 24. Whereas in Espirito Santo, the supply systems were inspected from November 27 to 29.

The Renova Foundation presented to the CTSHQA the time frames and proposal for the reassignment of deadlines for projects and construction works, as well as the indicators of this program. In Galilee (MG), the new ETA project and information about the municipality's alternative water withdrawal were presented at a hearing at the Town Council on November 21. In Governador Valadares, the following day, the alternative water withdrawal project was presented to the 10th District Attorney's Office.

In November, the installation of an alternative water supply system in Gesteira, in the municipality of Barra Longa (MG), was also completed. Its construction began in January 2017, with the drilling of a well for alternative water withdrawal in the area of the Health Center of Gesteira and, on November 24, the water treatment system and two new reservoirs were implemented. They are of polypropylene, of 5 thousand liters each, and already interconnected to the main system of the municipality.

The assessments of the Water Treatment Plants (ETAs) of Baixo Guandu, Resplendor, district of Mascarenhas (district of Baixo Guandu) and Senhora da Penha (district of Fernandes Tourinho) were validated by concessionaires. The reports of the ETA assessment of Cachoeira Escura (district of Belo Oriente) were issued. The executive project of the ETA of Linhares was also delivered.

The ETA of Regencia underwent replacement of equipment and its Operational Manual was created.

The SAAE of Mariana was sent the conceptual project of the System for Water Catchment, Pipelines and Distribution of public water supply of the locality Ponte do Gama, part of Camargos, district of the municipality.

The assessment of the ETAs of the Resplendor, Itueta and Santo Antonio do Rio Doce, in the district of Aimores, in Minas Gerais, were carried out, and their respective reports were issued.

The Study of Surface Water and Groundwater Capacities, conducted for the construction of alternative water supply systems to ensure water availability and security for the municipalities was filed with the Technical Board of Water Security and Quality (CTSHQA).

The assessment of the Baixo Guandu, Mascarenhas, Espirito Santo, São Tomé do Rio Doce, Resplendor, Itueta and Aimorés water treatment plant in Minas Gerais were completed and their reports submitted to the concessionaires.

The proposals of the municipalities of Resplendor and Itueta for alternative water withdrawal were presented to the Board of Local Councilors. The objective is to achieve a 30% independence regarding the water withdrawal from the Doce River.

Program activities are ongoing.

In Tumiritinga (MG), the cleaning and renovation of the Water Castle - a water tower - was carried out in São Tomé do Rio Doce, a district of the municipality. This improvement reestablishes the appropriate storage conditions and minimizes the risk of contamination of the treated water.

To guarantee water supply in the state of Espirito Santo (ES), while the Mobile Water Treatment Plant is undergoing improvements, one water tank of 15 thousand liters was installed, three of 10 thousand liters and another one of 5 thousand liters, in addition to the existing reservoir of 100 thousand liters, which will all be supplied by water tank trucks daily.

In addition, a 35,000-liter water cart will be available during the night time. Another 120 water tanks were installed in the residences to minimize the impact of a possible lack of water supply.

On May 22, 2017, the work schedule of the water security study was filed with the Inter-Federative Committee (CIF). This schedule will support the elaboration of projects to construct alternative systems for water withdrawal and supply and the promotion of improvements in the water treatment plants of the municipalities that withdraw from the Doce River.

Submitted to the Autonomous Water Sanitation Service (SAAE), the executive project for the renovation of the Water Treatment Plant in Regencia, district of Linhares (ES). Planned are the replacement of equipment, training of staff and installation of a waste treatment unit.

Directed towards the resumption of the water withdrawal from the Doce River, a workshop was held on treated water on April 10 and 11 at the Sanitation Company of Minas Gerais (Copasa), in Belo Horizonte (MG). The meeting was attended by representatives of the Technical Board (CT) of Water Safety and Quality, the CT of Health, Education, Culture, Leisure and Information and the CT of Communication; managers of the State Health Departments of Espirito Santo and Minas Gerais; managers of affected municipalities; representatives of the Renova Foundation and representatives of CBH-Doce.

During the event, proposals for monitoring the quality of water for human consumption were presented and discussed to evaluate its potability. In addition, the idea of a Communication Plan regarding the water for consumption distributed to the affected population was also discussed. The Technical Boards are preparing the minimum bases to send to the Foundation, so that the Foundation can elaborate these plans. These documents, when consolidated, will be part of the strategy of convincing the impacted populations in relation to the resumption of Doce River.

On the 9th, at the CIF meeting, CT Health was created, which will begin to conduct discussions on the monitoring of the water quality for human consumption and the Communication Plan. These documents will serve the strategy of persuading the population to resume the Doce River.

In Resplendor (MG) work was resumed to reinforce the Barroso stream dam. The objective of this activity is to allow the provisional water withdrawal from the Barroso stream, which will enable the demobilization of 13 water tank trucks. The works were put on hold, blocked by the owner and refusal of the mayor of the municipality to issue a Decree for Public Utility (DUP).

In the municipality of Bonisegna, the procedure of the community’s water supply was replaced, from cistern tank (which was without internal lining, which avoids contamination of the water via soil) to reservoirs supplied directly by water tank trucks. In the report previous to the water security study, no surface and underground wells were found in the reservoir region. Therefore, there is no estimation when the supplies by water tank truck will stop, because it all depends on the conclusion of the water security study in June.

The Water Security Study of nine municipalities and 15 districts in Minas Gerais and Espírito Santo was completed and the new filter system for treatment of groundwater originating from the tube well drilled in the São Tomé do Rio Doce district, in Galilean (MG), was tested.

In Baixo Guandu (ES), the water supply channel of the Guandu River was cleaned. In Colatina (ES), the lawn and the irrigation system of the football stadium were delivered. The drilling of wells in Marilândia (ES) was authorized by the State Agency for Water Resources (AGERH), as provided in the Action Plan for the Rainy Season 2016/2017.

Improvements were made to the water supply systems of the Water Treatment Plants (ETAs) of Belo Oriente (MG) and Regência (ES). Regarding alternative funding: in Tumiritinga (MG) a well filtration system was commissioned and in Colatina (ES) the water withdrawal system of the Pancas River was delivered. As part of the water supply assessment study, the consolidation of hydrological data has been initiated in the municipalities and districts mentioned in clause 171 of the Transaction and Conduct Adjustment Term (TTAC).

Improvements were made to the water supply systems of the Water Treatment Plants (ETAs) of Belo Oriente (MG) and Regência (ES). As part of the water supply assessment study, specialists were hired to prepare the scope of the technical part of this study related to surface and groundwater sources, whereas studies of the critical points have already been started. Finally, the topography and survey were completed of the route of the water pipeline of Suaçuí Grande to the Central ETA in Governador Valadares (MG), and also the conceptual engineering of alternative water withdrawal of Governador Valadares in Suaçuí Grande. The alternative withdrawals and the improvements to the water treatment systems are being carried out as part of the 2016/2017 Rainy Season Action Plan and may be validated as final, after the technical evaluation study of water supply of surface and groundwater sources.

The alternative withdrawals and the improvements to the water treatment systems are being carried out within the 2016/2017 Rainy Season Action Plan and may be validated as final, after the technical evaluation study of water supply of surface and groundwater sources.

Last month, two water pipelines were delivered in Espírito Santo, one in Linhares and another in Colatina. Furthermore, five deep wells were drilled, one in São Vitor, one in Cachoeira Escura, two in Alpercata and one in Itueta. The alternative withdrawals and the improvements to the water treatment systems are being carried out within the 2016/2017 Rainy Season Action Plan, which guidance of Witt O'Brien's.

In Colatina (ES) the construction works for building a water pipeline pump station from Santa Maria river has started, as well as the detailed engineering of the water pipeline and pump system of Pancas River. In Baixo Guandu (ES) and Governador Valadares (MG) the execution of the pipeline route topography has started. Last month the Barroso creek waters have been reassessed in Resplendor (MG).